Welcome to Humiq Hive Labs. By accessing or using our website humiqhivelabs.com and our services, you agree to be bound by the following Terms and Conditions. Please read them carefully before using our website or engaging with our services.
Important Notice: These terms constitute a legally binding agreement between you and Humiq Hive Labs. Please read them carefully before proceeding with any transaction or project engagement.
By visiting our website, contacting us, or using our services, you agree to comply with these Terms and Conditions. If you do not agree with any part of these terms, please do not use our website or services.
Humiq Hive Labs provides professional technology and software services, which may include:
The exact scope of work for each project will be defined in the client agreement, proposal, estimate, or project discussion.
All client work is governed by mutually agreed project terms. These terms may include:
No work will proceed beyond the agreed scope unless both parties approve the changes.
Payments may be milestone-based, hourly-based, advance-based, or as mutually agreed. Delayed payments may result in suspension of work until dues are cleared.
Payments must be made within the agreed timeframe. Delayed payments may result in suspension of work until dues are cleared.
Clients agree to:
We are not responsible for delays caused by missing client input, late approvals, or inaccurate information shared by the client.
Unless otherwise agreed in writing:
We respect client confidentiality. Any sensitive project information, business data, or agreement details shared with us will be treated as confidential and used only for project execution and related communication, unless disclosure is required by law.
Project timelines are estimated based on the agreed scope and timely client communication. We will make reasonable efforts to meet delivery deadlines.
Revisions, if included, will be handled according to the project agreement. Additional work outside the agreed scope may require extra charges and additional time.
Humiq Hive Labs shall not be liable for:
Our total liability, if any, shall be limited to the amount paid by the client for the specific service in question.
Some services may depend on third-party tools, APIs, libraries, hosting providers, or platforms. We are not responsible for the performance, availability, or policies of third-party services.
Either party may terminate a project or agreement by written communication, subject to the terms already agreed between the parties. In case of termination, payment for completed work and expenses already incurred may still be required.
We may update these Terms and Conditions from time to time. Changes will be effective when posted on this page. Continued use of our website or services means you accept the updated terms.
These Terms and Conditions shall be governed by and interpreted in accordance with the laws of India, and any disputes shall be subject to the jurisdiction of the courts located in Punjab, India.
If you have any questions about these Terms and Conditions, please contact us at: